|
- ASSIGNMENT
Neither this Contract nor the consideration due hereunder may be assigned by Seller, in whole or in part, without Buyer's prior written consent.
- CHANGES
- Seller shall not furnish extra services, labor, materials, or equipment in the performance of this Contract unless this Contract is changed to require such extra services, labor, materials, or equipment.
- Buyer may at any time, by written order, make changes to this Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of this Contract, Buyer shall make an equitable adjustment in the Contract Price, the performance or delivery schedule, or both, and shall so modify this Contract. If Buyer changes the Contract performance or delivery date(s) such that Seller is required to work overtime, Buyer shall pay therefor an amount equal only to Seller's actual additional labor costs occasioned by such overtime.
- Buyer’s facilities, engineering and technical personnel may from time to time render assistance or give technical advice or discuss or exchange information with Seller’s personnel concerning the Contract Work. Such actions, however, shall not be deemed to be a change under this Changes paragraph and shall not be the basis for any equitable adjustment. Only an authorized representative of Buyer’s Purchasing Department may change this Contract
- Within twenty (20) days from the date of receipt of any written change order, Seller shall submit to Buyer a detailed written estimate of the impact of the change on the Contract Price, the performance or delivery schedule, and the performance capabilities of any Contract Products. Upon receipt of this estimate, Buyer shall begin good faith negotiations with Seller to determine an equitable adjustment to the Contract.
- The failure of the parties to agree to any equitable adjustment shall be a dispute under the Disputes paragraph of this Contract. Nothing in this Changes paragraph, however, shall excuse Seller from proceeding with diligent performance of this Contract as changed.
- CLEAN-UP OF WORK SITE
During the performance of this Contract, and upon completion of the Contract Work or earlier termination of this Contract, Seller shall remove all debris, garbage or other waste material, including excess materials, scrap and equipment used or generated in performance of this Contract from Buyer's facilities. Seller shall be liable for and shall pay to Buyer, upon demand, all costs of removal for materials or equipment not so removed.
- COMPLIANCE WITH LAW
Seller shall, in the performance of this Contract, fully comply with all applicable federal, state and local laws, rules, regulations, orders, conventions, ordinances and standards that relate to the Contract Work. Seller shall defend, indemnify and hold Buyer harmless from any and all claims and liabilities resulting from any failure to so comply.
- CONFIDENTIALITY OF DATA AND INFORMATION
Information furnished by Buyer and identified by Buyer as "NASSCO Proprietary/Trade Secret Information" or otherwise identified as subject to restricted access or dissemination shall be and remain property of Buyer; shall not be duplicated, used or disclosed to third parties except for the purpose and to the extent necessary for the performance of this Contract; and upon completion of this Contract, shall be delivered to Buyer or destroyed by Seller as Buyer specifies (including all copies). Seller shall take all reasonable precautions to maintain in confidence all such information, including the imposition upon any person, firm, or corporation to whom disclosure of such information is made in the course of performance under this Contract of conditions relating to the confidential treatment thereof to the same effect as those imposed upon Seller herein. The obligations imposed upon Seller herein shall not apply to such information that is already known to Seller, is lawfully obtained or obtainable by Seller from another source, is or comes into the public domain other than as a result of breach of this Confidentiality of Data and Information paragraph.
- CONTRACT ACCEPTANCE, INTEGRATION AND MODIFICATION
- Seller shall strictly perform this Contract. Acceptance of this Contract is expressly limited to the terms and conditions hereof and shall be made by executing the "acknowledgment copy" of the purchase order and returning the same to Buyer. If for any reason Seller should fail to accept this Contract in writing, any performance by Seller of any portion of this Contract shall constitute complete acceptance of this Contract. Any terms proposed in the acceptance of this Contract, which add to, vary from, or conflict with the terms and conditions of this Contract, are hereby objected to and shall be void.
- This Contract constitutes the entire agreement between the parties and supersedes all previous communications, representations or agreements, whether oral or written, between the parties. No terms other than those set forth herein or in the purchase order shall apply. Seller represents that, in entering into this Contract, it does not rely on any previous oral or implied representation, inducement, or understanding of any kind.
- This Contract may be amended or modified only by a written instrument executed by authorized representatives of both Buyer and Seller.
- CONTRACTOR'S LICENSE
Seller represents and warrants that Seller (not a parent, affiliate or subsidiary of Seller) holds a current, valid California Contractor’s License to perform the Contract Work, that Seller’s license designation and number are as stated in the purchase order, and that Seller will remain in good standing with the Contractors State Licensing Board and shall maintain its license in full force and effect during the performance of the Contract Work and until the expiration of the Warranty Period (as defined in the Warranty paragraph).
- DEFINITIONS
- "Buyer" means National Steel and Shipbuilding Company.
- "Contract" means the purchase order, these Terms and Conditions, the Specifications, and any other documents incorporated by referenced by the purchase order.
- "Contract Price" means the total price to be paid by Buyer to Seller for the proper performance of the Contract Work as set forth in this Contract.
- "Contract Products" means the products, goods, material, supplies, equipment, articles or data to be furnished by Seller.
- "Contract Work" means the design and construction services to be performed by Seller under this Contract. Unless otherwise specifically defined, "Contract Work" includes any Contract Products.
- "Seller" means the individual or entity identified on the face of the purchase order by whom the Contract Work is to be performed.
- "Specifications" means the technical specifications, plans, data, drawings, diagrams, schedules, proposals, and any other documents that describe the Contract Work.
- DIFFERING SITE CONDITIONS
- Seller shall promptly, before conditions are disturbed, and in no event later than five (5) days after first observance of the conditions, give written notice to Buyer of:
- Subsurface or latent physical conditions at the site which differ materially from those indicated in the Specifications and all documents referenced in the Specifications to this Contract; or
- Unknown physical conditions at the site, of an unusual nature, which Seller believes differ materially from those ordinarily encountered and generally recognized as inhering in Contract Work of the character provided for in this Contract, and which Seller believes materially affect Seller’s ability to perform the Contract Work.
- Buyer shall investigate the site conditions promptly after receiving written notice. If Buyer determines that the conditions do materially differ and cause an increase or decrease in the Seller's cost of, or the time required for, performing any part of the Contract Work or furnishing of Contract Products under this Contract, an equitable adjustment shall be made to the Contract Price and the Contract modified in writing accordingly. If Buyer determines that the conditions do materially differ, Buyer shall determine the proper steps for resolving the differing conditions.
- A request for an equitable adjustment to the Contract Price for differing site conditions shall only be allowed if made in writing immediately upon manifestation of such conditions to Seller and before such conditions are disturbed.
- DISPUTES
- Any dispute between Buyer and Seller in connection with or arising out of this Contract shall be resolved by means of the following procedures:
- The dispute initially shall be referred to each party’s senior executive with responsibility for this Contract, who shall negotiate in good faith to reach a resolution of the dispute.
- In the absence of a resolution being achieved within thirty (30) days after either Buyer or Seller offers to conduct the negotiations in subparagraph (a)(i), above, either party may take appropriate action pursuant to subparagraph (b) hereof.
- Any dispute not resolved in accordance with subparagraph (a), above, may be resolved by any lawful means, including litigation, which shall be initiated by either party in a court of competent jurisdiction in San Diego County, California, and both parties consent to such exclusive jurisdiction and venue.
- In resolving any dispute under this Contract, the prevailing party shall be entitled to recover from the other party all reasonable attorney's fees and costs incurred.
- Until final resolution of any dispute hereunder, Seller shall diligently proceed with the performance of this Contract as directed by Buyer.
- ENVIRONMENTAL
Seller shall comply with Buyer’s environmental policies and procedures and with all federal, state and local laws and regulations regarding air quality and the use and disposition of hazardous substances, and Seller represents and warrants that it is aware of all such policies, procedures, laws and regulations. Seller shall defend, indemnify and hold Buyer harmless from any and all loss, costs and expenses, including, but not limited to, attorneys fees, arising to any extent from Seller’s failure to perform its obligations hereunder, negligent or otherwise.
- EXPORT CONTROL COMPLIANCE AND COOPERATION
Seller shall comply with the Export Administration Regulations (15 CFR 730—774) and the regulations issued by the Office of Foreign Assets Control (31 CFR Chapter V), all other applicable laws, regulations and orders that control the export of commercial and dual-use items and associated technology. In addition, Seller shall inform Buyer in writing of the name and citizenship of each employee of Seller and Seller’s subcontractors at any tier who will participate in the performance of this Contract at Buyer’s facilities who is not a United States citizen or lawful permanent resident and the name and address of each subcontractor at any tier who will participate in such performance that is not organized under the laws of any state of the United States. Seller shall cooperate fully with Buyer in applying for any export license or approval which may be required for any such employee or subcontractor and in justifying and documenting any license or approval exception. Seller shall not permit any such employee or subcontractor to participate in the performance of this Contract over Buyer’s objection based on noncompliance with this Export Control Compliance and Cooperation paragraph. Buyer assumes no responsibility for any conclusions or interpretations made by Seller based on the Specifications and all documents referenced in the Specifications made available by Buyer.
- INDEMNITY
Seller shall defend, indemnify and save Buyer, its affiliated companies, and each of their directors, officers, agents and employees, free and harmless from and against all claims and liabilities of any nature, and all costs and expenses incurred in connection therewith (including, but not limited to, attorneys fees) for death or injury to persons (including, but not limited to, agents and employees of Seller and its subcontractors) and for damage or loss of property arising directly or indirectly out of or in connection with the performance of this Contract, including, without limitation, claims and liabilities based in whole or in part on the negligence or other theory of liability of Seller or Seller’s subcontractors, and excluding only claims and liabilities based on Buyer’s sole negligence or willful misconduct.
- INDEPENDENT CONTRACTOR
In performing this Contract, Seller and its employees and subcontractors shall be an independent contractor to Buyer and shall not be an agent or employee of Buyer. Seller shall be solely responsible for determining the means and methods of performing this Contract. Seller assumes full responsibility for the payment of all compensation, expenses, and benefits (including, but not limited to, Workers' Compensation, medical, and other benefits) to its employees and for all state and federal income tax, unemployment insurance, social security, disability insurance, and other applicable withholdings.
- INSPECTION AND ACCEPTANCE
The Contract Work, including any documents, materials, equipment, and facilities, shall at all times be available for inspection and testing by Buyer. Buyer's inspection or failure to inspect shall not relieve Seller of any obligations or liability under this Contract, nor shall it constitute acceptance of the Contract Work. Seller shall repair, reperform or replace any nonconforming Contract Work at Seller's expense within ten (10) days of Buyer's written notice of nonconformance. If Seller has not repaired. reperformed or replaced such nonconforming Contract Work within the 10-day period, Buyer may repair, reperform or replace such nonconforming Contract Work at Seller's expense. The Contract Work shall be accepted when Buyer determines, and states in writing, that the Contract Work conforms to this Contract, and such acceptance shall be conclusive of conformance except for latent defects, fraud or gross negligence.Each such insurance policy shall be underwritten by an insurance company satisfactory to Buyer, shall provide that it is primary insurance to, and noncontributing with, any other insurance carried by Buyer, and shall obligate the insurer to give Buyer not less than thirty (30) days prior written notice in the event of policy cancellation or any material change therein. Each policy, except for professional liability, shall name Buyer as an "additional insured." Certificates evidencing such policies, in a form satisfactory to Buyer, shall be delivered to Buyer upon the Seller's execution of this Contract, and renewals thereof shall be sent to Buyer at least ten (10) days prior to the expiration of the respective policy terms. Buyer shall have the right to withhold payment of sums due under this Contract until such certificates or renewals are received.
- INSURANCE
- Without prejudice to Buyer’s rights and Seller’s obligations under the Indemnity paragraph herein, Seller shall keep and maintain in effect at its sole cost and expense the following policies of insurance:
- Commercial General Liability insurance with coverage to include broad form property damage, personal injury, premises, completed operations, and products and contractual liability (specifically insuring the liability assumed under this Contract); and with a minimum bodily injury and property damage combined single limit of $2,000,000 per occurrence and $2,000,000 in the aggregate.
- Commercial Automobile Liability insurance with coverage to include owned, hired, and non-owned vehicles; and with a minimum bodily injury and property damage combined single limit of $2,000,000 per occurrence.
- Workers' Compensation and Longshore and Harbor Workers' Compensation Act insurance with limits conforming to the statutory requirements of the State of California and the United States of America, respectively.
- If Seller or its employees are assigned aboard a vessel for any reason and to any extent, Jones Act coverage with minimum limits of liability of $2,000,000 per occurrence and $2,000,000 in the aggregate.
- If required on the face of the purchase order, Seller shall keep and maintain in effect at its sole cost and expense professional liability (errors and omissions) coverage with minimum limits of liability of $1,000,000 per occurrence and $1,000,000 in the aggregate.
- Each such policy shall be underwritten by an insurance company satisfactory to Buyer; shall provide that it is primary insurance to, and noncontributing with, any other insurance carried by Buyer; and shall obligate the insurer to give Buyer not less than thirty (30) days prior written notice in the event of policy cancellation or any material change therein. Certificates evidencing such policies, in a form satisfactory to Buyer, shall be delivered to Buyer upon issuance of the purchase order, and renewals thereof shall be sent to Buyer at least ten (10) days prior to the expiration of the respective policy terms. The policies referred to above in subparagraphs (a)(1) and (a)(2) shall be endorsed to name Buyer as an "additional insured," and the certificates provided to Buyer shall reflect such endorsement. The policies referred to above in subparagraphs (a)(3) and (a)(4) shall contain a waiver of subrogation in favor of Buyer.
- Notices regarding insurance policies shall be provided in writing and shall be deemed delivered five (5) days after deposit in the U.S. Mail, postage prepaid, certified mail and return receipt requested, when addressed to National Steel and Shipbuilding Company, Attention: Risk Manager (M/S 20-E), P.O. Box 85278, San Diego CA 92186-5278.
- The insurance coverage limits stated above are minimum insurance coverage requirements, not limits of Seller’s liability. Notwithstanding the above-required insurance policies, Seller shall be obligated for the full and total amount of any damage, injury, expense or loss.
- INTERPRETATION
This Contract shall be enforced and interpreted under California law without regard to which party drafted the Contract or to California's choice of law provisions. If any provision of this Contract is determined to be unenforceable, all other provisions shall remain in effect. This Contract shall not be varied, supplemented, qualified or interpreted by any prior course of dealing or usage of trade. Paragraph headings are for convenience only and shall not be used to interpret this Contract. In the event of any conflict or inconsistency between any provisions of this Contract, the following precedence shall be followed: the purchase order; these Terms and Conditions; the Specifications; any other document incorporated by reference by the purchase order.
- INVOICES AND PAYMENT
- Invoices shall include: the purchase order number; the invoice number; description of all Contract Work performed; the dates of performance; comprehensive, itemized prices; prior payments received; terms; and discounts. Unless otherwise provided, any cash discount period shall commence on the date of receipt of Seller's invoice. Incorrect and incomplete invoices shall be returned for correction and shall delay the commencement of Buyer's obligation to pay for the Contract Work and any discount period, until a corrected invoice is received by Buyer.
- Buyer shall pay Seller within thirty (30) days from receipt of a proper invoice by Buyer.
- Buyer shall pay Seller only for the complete, proper and timely performance of this Contract, and Buyer shall have the right to withhold payment for any failure of Seller to strictly comply with this Contract. No payment of any portion of the Contract Price shall constitute acceptance of the Contract Work.
- Buyer may withhold payment of five percent (5%) of the Contract Price as retainage until Seller completes and Buyer accepts the Contract Work, and Buyer may withhold an additional five percent (5%) of the Contract Price as retainage until the Warranty Period expires and Seller has satisfactorily corrected any deficiencies in the Contract Work arising during the Warranty Period.
- LIENS
- Seller waives any and all rights to any lien against Buyer by Seller or Seller’s subcontractors.
- Buyer shall have the right to withhold any payment until Seller shall furnish, as requested, current written releases and waivers of all rights to claim or file liens, properly executed by Seller and its subcontractors. Seller’s acceptance of full payment of the Contract Price shall constitute satisfaction in full and release of all claims or demands of Seller and its subcontractors against Buyer arising out of or connected with this Contract. If Seller fails or neglects to pay any admitted claims for labor or material, Buyer may pay such claims and deduct such payments from funds due Seller hereunder or, if such claims be disputed, withhold sufficient funds to pay such claims until they are resolved. Seller shall immediately discharge or cause to be discharged any lien or charge of any kind which at any time is filed against the property of Buyer with respect to, or arising from, the performance of the Contract Work. If any such lien or charge is not immediately discharged, Buyer may discharge or cause to be discharged such lien or charge at the expense of Seller.
- NONWAIVER
Buyer's waiver of any provision of this Contract shall not constitute wavier of that provision in any later circumstances or waiver of any other Contract provision.
- NOTICES
Unless expressly directed otherwise, notices required by this Contract to be given by Seller or Buyer to the other party shall be personally served upon Seller or Buyer or served by facsimile and first class mail addressed to the appropriate address hereinafter set forth or to such other address as Seller and Buyer may hereafter designate by written notice. If served by facsimile and first class mail, service will be considered complete and binding on the party served immediately upon completion of said facsimile transmission, as evidenced by a confirmation of successful transmission.
To Seller:
As indicated on face of the purchase order
To Buyer:
National Steel and Shipbuilding Company
P.O. Box 85278
San Diego, California 92186-5278
Attn: Manager, MRO Purchasing
Facsimile Number: (619) 544-3677
- PAYMENT BONDS
Upon Buyer's sole discretion determination that Seller is unable to pay all of its suppliers and subcontractor’s in a timely manner or is unable assure timely performance, Buyer may request, and upon such request Seller shall provide, payment (labor and material) bonds in amounts designated by Buyer and issued by surety companies acceptable to Buyer. Seller's failure to provide such bonds upon request shall constitute a material breach of this Contract.
- PERFORMANCE BOND
Seller shall provide, effective upon commencement of performance of this Contract, a performance bond with surety and bond language sufficient to Buyer, in the full amount of the Contract Price. Seller's failure to provide such bond shall constitute a material breach of this Contract.
- PROPERTY RIGHTS IN THE CONTRACT WORK
All data and materials prepared or developed by Seller in connection with the performance of the Contract Work shall be Buyer's exclusive property and shall be provided to Buyer upon completion of performance of this Contract, upon termination of this Contract, or upon Buyer's earlier request.
- REMEDIES
All remedies are cumulative, and the exercise of a remedy conferred by this Contract or in law or equity shall not preclude the exercise of any other remedy under this Contract or in law or equity.
- SAFETY
- Seller shall be solely responsible for the safe conduct of all persons employed by Seller and its subcontractors. Seller shall comply with all applicable federal, state, and local health, safety and fire protection laws and regulations. Seller shall also comply with Buyer's safety policies and procedures. Any failure by Seller or any of its suppliers to comply with any such safety policies, procedures, laws or regulations shall constitute a material breach of this Contract. Under no circumstance shall compliance with Buyer's safety policies and procedures alone be considered complete satisfaction of the requirements of this subparagraph.
- Seller shall complete the following prior to commencement of performance of the Contract Work at Buyer’s facilities:
- Provide to Buyer's Safety Department the name, telephone number and title or position of the person who has the authority to correct any safety violations by Seller during the performance of this Contract ("Seller’s Safety Representative").
- Seller's Safety Representative, together with equivalent representatives of Seller’s subcontractors who are expected to perform at Buyer's facilities, shall meet with Buyer's Safety Manager or designee to review applicable safety policies and procedures.
- Provide to Buyer's Safety Department a copy of Seller's written safety policies and procedures.
- Provide to Buyer's Safety Department a copy of all Material Safety Data Sheets ("MSDS") for all chemical compounds that Seller anticipates using in performing this Contract at Buyer's facilities.
- Cause each of Seller’s and Seller’s subcontractor’s employees who will be in Buyer's facilities to complete a "Personal Protective Equipment" statement acknowledging their safety responsibilities.
- Seller shall immediately notify Buyer's Safety Department, in writing, upon receiving notice of any inspection from either United States OSHA or California OSHA representatives of their work area at Buyer's facilities. In the event of such an inspection, Seller shall permit Buyer's personnel to be present at any opening conference, the inspection, and any closing conference, and Seller shall provide Buyer with copies of all correspondence, including citations, received from OSHA or Cal OSHA.
- If, in Buyer's sole opinion, Seller fails to comply with this Safety paragraph, Buyer, may without prejudice to any other legal or contractual rights of Buyer, issue an order stopping all or part of Seller’s performance. Seller shall have no claim for extension of time or for compensation or damages by reason of or in connection with such work stoppage.
- Seller shall remove from Buyer's facilities any of Seller’s or Seller’s subcontractor’s employees immediately upon Buyer's request based upon (in Buyer's sole opinion) violation of Buyer's safety policies or procedures or violation of applicable federal, state or local safety laws or regulations.
- SCOPE OF PERFORMANCE
Seller shall supply and furnish at the location where the Contract Work is to be performed all design services, labor, materials, equipment, tools, services, transportation, and supervision, and shall bear all items of expense, necessary for the complete and satisfactory performance of this Contract, except such items that Buyer, in this Contract, specifically agrees to supply or furnish to or for the use of Seller. Any design services, labor, materials, equipment, tools, services or supervision not specifically described in this Contract, but which may be fairly implied as required thereby or necessary to properly complete the Contract Work, shall be deemed within the scope of the Contract Work and shall be provided by Seller.
- SECURITY
Seller shall comply with Buyer's security policies and procedures regarding personnel administration, vehicle operations, and general security practices. Willful or repeated negligent noncompliance by Seller or any of its subcontractors with any such security policies or procedures shall constitute a material breach of this Contract.
- SITE INVESTIGATION AND CONDITIONS AFFECTING CONTRACT WORK
- Seller represents that it has taken steps reasonably necessary to ascertain the nature and location of the Contract Work, and that it has reviewed and understands the Specifications and all documents referenced in the Specifications, and has satisfied itself as to the general and local conditions which can affect the Contract Work, Contract Products or the Contract Price, including but not limited to: (i) conditions bearing on transportation, disposal, handling, and storage of materials; (ii) the availability of labor, water, electric power, and roads; (iii) the conformation and conditions of the ground; (iv) the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered; and (v) conformance to Buyer's shipyard production schedule. Seller shall have sole responsibility for properly estimating the difficulty and cost of successfully furnishing the Contract Products or performing the Contract Work, and for proceeding to successfully furnish the Contract Products or perform the Contract Work without additional expense to Buyer.
- Buyer assumes no responsibility for any conclusions or interpretations made by Seller based on the Specifications and all documents referenced in the Specifications made available by Buyer.
- STANDARD OF PERFORMANCE
- Seller shall perform the Contract Work using reasonable diligence, exercising its best judgment, and using the care and skill ordinarily used by reputable similar persons or entities in providing the same or similar services under similar circumstances. Seller is on notice that Buyer is relying on the care, skill, diligence and judgment exercised by Seller in performing the Contract Work.
- Seller shall be responsible to the Buyer for acts and omissions of the Seller’s employees, subcontractors, and their agents and employees, and other persons, including engineers, and other design professionals, performing any portion of the Seller’s obligations under this Contract.
- If Seller subcontracts any portion of the Contract Work, Seller shall provide Buyer with the name and address of such subcontractor prior to executing such subcontract. Buyer may decline the usage of such subcontractor based on Buyer’s independent evaluation of subcontractor’s qualifications.
- The Contract Products and their components shall be new and of suitable grade of their respective kinds for their purpose. Upon Buyer's request, Seller shall furnish full information concerning the origin, quality and condition of the components of the Contract Products.
- Design services required by this Contract shall be performed by qualified engineers and other design professionals, licensed in the State of California. The contractual obligations of such professional persons or entities are undertaken and performed in the interest of the Seller.
- SUBMITTALS AND APPROVALS
- Seller shall promptly submit to Buyer all documents that require Buyer’s review and approval, and Buyer shall promptly approve or reject Seller’s submittals
- Approvals provided by Buyer under this Contract, however, shall not relieve Seller of its obligation to comply with all terms of this Contract and shall not impose upon Buyer any obligation or liability that Buyer would not have had in the absence of such approvals.
- TERMINATION
- For Convenience: Buyer may terminate this Contract for convenience at any time without prior notice.
- For Default: Buyer may terminate this Contract for default if Seller: fails to assure timely performance; fails to perform on time; ceases performance prior to completion; evidences insolvency or financial inability to perform; fails to pay its suppliers and subcontractors in a timely manner; or fails to cure the material breach of any other provision of this Contract within ten (10) days of notice of such breach.
- In the event Buyer terminates this Contract for default in whole or in part as provided in subparagraph (b) above, Buyer may procure, upon such terms and in such manner as Buyer may reasonably determine, goods or services similar to the Contract Work and Contract Products specified herein, and Seller shall be liable to Buyer for any excess costs for such similar procurement. If this Contract is terminated only in part, Seller shall continue the performance of this Contract to the extent not terminated.
- Upon termination of this Contract, either for convenience or for default, Seller shall immediately cease performance of the Contract Work, shall immediately return to Buyer all information, materials and documents acquired from Buyer, and shall immediately provide to Buyer all information, materials and documents prepared or developed by Seller in connection with performance of the Contract Work. Further, Seller’s obligations as set forth in the Property Rights in the Contract Work and Confidentiality of Information paragraphs, shall survive any termination of this Contract either for convenience or for default.
- THIRD PARTY RIGHTS
This Contract is intended solely for the benefit of Buyer and Seller and is not intended for the use or benefit of any other party. Nothing contained in this Contract is intended to make any person or entity that is not a signatory to this Contract a third party beneficiary of any right created by this Contract.
- TIME OF PERFORMANCE
- Seller shall perform this Contract in a diligent manner and in no event later than the time(s) specified on the face of the purchase order. Time of performance specified in this Contract is of the essence of this Contract. If at any time it reasonably appears to Buyer that Seller is failing to make progress, such that performance may not be completed in accordance with this Contract, Seller shall, within seven (7) days of a written request by Buyer, assure timely performance and represent to Buyer in writing Seller’s best completion date. If the represented completion date is not within the original time for completion of performance of this Contract, Buyer may terminate this Contract for default in accordance with the Termination paragraph. Buyer shall further have the right, but not the duty, and without waiver of any other rights and remedies that it may have, to extend the time for completion of performance. The new date for completion of performance shall be final, of the essence of this Contract, and subject to further change only in accordance with this Contract.
- Seller shall not be liable for delays caused by force majeure events that are beyond the control and without the fault or negligence of the Seller, including, but not limited to, acts of God or the public enemy, fires, earthquakes, floods, epidemics, quarantine restrictions or natural disasters, on condition that Seller notifies Buyer of any such force majeure events within five (5) days of the start of any such delays. Seller shall cooperate with Buyer, and Seller shall use its best efforts, to recover any such delays caused by any such force majeure events.
- TREATMENT AT BUYER'S MEDICAL FACILITIES
Buyer shall have no obligation to furnish medical treatment to Seller's or Seller’s subcontractor’s employees while such employees may be working in Buyer's facilities. In the event Buyer's Medical Department furnishes medical treatment to any such employee, Seller shall defend, indemnify and hold harmless Buyer, its affiliated companies, and the directors, officers and employees of each of them, from and against any and all claims, demands or causes of action, by Seller's employees or their representatives, heirs or assigns for costs or damages (including without limitation punitive damages and reasonable attorney fees) arising out of or in connection with medical treatment furnished by Buyer, including claims based upon the negligence of Buyer, and excluding only claims based on Buyer’s sole negligence or willful misconduct.
- USE OF BUYER'S EQUIPMENT
Seller shall not use, or permit any third party to use, any of Buyer's equipment, tools, devices, apparatus or property ("Buyer's Equipment") without Buyer's express, written consent. If Buyer so consents, Seller shall ensure that only qualified, properly trained persons use Buyer's Equipment and that such persons obey all of Buyer's applicable use procedures and requirements and all applicable federal, state and local laws and regulations. If Buyer so consents, Buyer's Equipment is provided "as-is," with no warranty, express or implied, as to its merchantability, fitness for any particular purpose, current condition, or prior maintenance history. Seller is responsible for all risk of loss of or damage to Buyer's Equipment used by Seller.
- WARRANTY
- Seller expressly warrants for a period of one (1) year from acceptance by Buyer ("Warranty period") that all Contract Work shall conform to this Contract, be performed in a proper and workmanlike manner, and be free from defects in design, material, workmanship and fabrication. If any nonconformities or defects are discovered in the Contract Work during the Warranty Period, which are not caused by Buyer, Seller shall repair, replace or reperform any nonconforming or defective Contract Work at Seller's sole expense within ten (10) days of Buyer's written notice. If Seller has not repaired, replaced or reperformed such nonconforming or defective Contract Work or Contract Products within the 10-day period, Buyer may repair, replace or reperform such nonconforming or defective Contract Work or Contract Products at Seller's expense.
- Seller hereby assigns to Buyer all warranties provided by the manufacturers of all Contract Products and their components.
|
|
|
|
|
